Terms & Conditions

Welcome to JEERISEEN SOFTWARE. These Terms and Conditions outline the rules and regulations for the use of our website and the provision of our software development services. By accessing this website or engaging our services, you accept these terms in full.

1. Engagement of Services

  • Scope of Work: All services provided by Jeeriseen Software will be defined in a separate Statement of Work (SOW) or Service Agreement. Any changes to the scope after the project start may incur additional fees.

  • Consultations: Initial consultations are provided to understand project requirements. We reserve the right to decline any project that does not align with our technical capabilities or ethical standards.

2. Intellectual Property (IP)

  • Client Ownership: Upon full and final payment, the custom code and final deliverables created specifically for the Client will become the property of the Client, unless otherwise specified in the Service Agreement.

  • Agency Rights: Jeeriseen Software retains ownership of any pre-existing code, proprietary frameworks, or “base” libraries used in the development process. We also reserve the right to feature the completed project in our professional portfolio unless a Non-Disclosure Agreement (NDA) prohibits it.

3. Payment Terms

  • Deposit: A non-refundable commencement fee (typically 40–50%) is required before project kickoff.

  • Milestones: For larger projects, payments are structured around specific development milestones.

  • Late Payments: We reserve the right to suspend development or withhold the transfer of final files if payments are not made according to the agreed schedule.

4. Client Responsibilities

  • Information Accuracy: The Client is responsible for providing clear requirements, timely feedback, and any necessary assets (logos, content, API access).

  • Delays: Delays caused by the Client’s failure to provide information may result in a shift in the final delivery timeline.

5. Warranties & Support

  • Bug Fixes: We provide a 30-day post-launch warranty to fix any bugs or errors identified in the original scope of work.

  • Maintenance: Ongoing maintenance, server management, and updates after the warranty period are subject to a separate Maintenance Agreement.

  • Third-Party Services: We are not liable for issues caused by third-party services (e.g., AWS, Google Cloud, payment gateways like MoMo/Stripe) that are beyond our control.

6. Limitation of Liability

To the maximum extent permitted by the laws of Ghana, Jeeriseen Software shall not be liable for any indirect, incidental, or consequential damages (including loss of profits or data) arising out of the use or inability to use the developed software.

7. Termination

Either party may terminate a project if the other party breaches these terms. Upon termination, the Client shall pay for all work completed up to the date of termination.

8. Governing Law

These Terms and Conditions are governed by and construed in accordance with the laws of the Republic of Ghana. Any disputes arising from these terms shall be subject to the exclusive jurisdiction of the courts in Accra, Ghana.

9. Contact Information

If you have any questions regarding these Terms, please contact us:

Scroll to Top